Rahul Sharma

Metropolitan Water Board v Dick, Kerr and Co Ltd

Updated on
Share on FacebookTweet on TwitterShare on LinkedIn
Court  House of Lords
Citation(s)  [1918] AC 119
Metropolitan Water Board v Dick, Kerr & Co Ltd httpsuploadwikimediaorgwikipediacommonsthu
Similar  Davis Contractors Ltd v Fare, Krell v Henry, Taylor v Caldwell

Metropolitan Water Board v Dick Kerr and Co Ltd [1918] AC 119 is an English contract law case, concerning the frustration of an agreement.

Contents

Facts

Dick, Kerr & Co agreed to build a reservoir in six years for the Metropolitan Water Board (London). The contract said that Dick, Kerr & Co should apply to the engineer for an extension of time in the event of delay ‘whatsoever and howsoever occasioned’. Dick, Kerr & Co were then required to stop work and sell their plant because of a Government Order.

Judgment

The House of Lords held that the contract was frustrated, because the delay clause was intended to cover temporary difficulties, and not such fundamental changes in the contract’s nature.

References

Metropolitan Water Board v Dick, Kerr & Co Ltd Wikipedia


Similar Topics
Krell v Henry
Taylor v Caldwell
Luponini from Chicago
Topics